CONTRACT
No:
Date: Sign at:
Buyers:
Address:
Tel: Fax: Telex: Cable:
Sellers:
Tel: Fax: Telex: Cable:
The undersigned sellers and buyers have agreed to close the following transactions according to the terms and conditions stipulated below:
1. Subject of Contract
Both parties agree that on the principle of equality and mutual benefit the buyers will purchase the following commodities from the sellers. Their name, specification,quantity,unit price and amount fully detailed in annex No. . All the annexes to the contract are inseparable parts of the contract.
2. Total Value
3. Terms of Delivery: (DAF, CLF, FOB) …
The terms of delivery are subject to INCOTERMS formulated by International Chamber of Commerce unless otherwise provide. The sellers have the option to load % more or less than the quantity contracted.
4. Origin of Commodity:
5. Packing:
6. Time of Delivery:
7. Port of Delivery & Destination:
8. Insurance:
9. Terms of Payment:
This contract adopts the settlement term by (a.L/C b. Collection: D/P sight or D/A c. Remittance: M/T or T/T)
A(1) The buyers should open a L/C (irrevocable, documentary,
confirmed/unconfirmed, sight, transferable, revolving, reciprocal, partial shipment allowed/not allowed)though the opening bank in sellers’favour.This L\C remain valid in beneficiary’s country within days after the delievery.
(2)When the advising bank receives an irrivocable L\C issned by the buyers,the sellers should ask bank to open % of the L\C amount to the opening bank as a margin.The whole amount of the margin will be returned to the sellers after commodities the are loadsde and delivered.If the commodities can not be delivered wholly or partly on time for the reason other than those stipulated in clause 13,the margin should be paid to the buys as a penalty as stipulated in clause 11.
B After the commodities are loaded ,the sellers should draw a draft for buyers’account in the term of[①:document bill—D\P sight;②: D\Asight upon the buyers’acceptance on days].The sellers passed on documents to the buyers thuough sellers’bank or bank,The buyers (effect payment according to the term of the term of the draft,orbarter with the sellers )
C The buyers should effect payment by M\T or T\T with in days after receiving the documents presented by sellers as stuipulated in clause 10.
D When the commodities reach the designed frontier station and come into the disposal of the buyers,the delivery is supposef to be completed .The ownship and the risk of accidental of accidental loss or quality damage to the commodities are transfered form the sellers to buyers ,The buyers settle with the sellers by the bill of lading to a named consignee within days [upon,after ,or before]the seller’s delivery.
10.The seller should present the following documents:
(1)Full set of clean bills of lading made out to order and blank endorsed,mared [freight perpaid\payable at destimnation] in copies.
(2)Signed commercial invoice in copies.
(3)Certifical of origin in copies.
(4)Packing list in copies
(5)Inspection certificate on quality and weight in copies
(6)Insurance policy \certificate covering CIF in Copies
11.Penalty
In case of delay or failure in delivery or payment,the party in breach should pay. The penalty to the other party, unless it is for the reason stipulated in clause 13. The amount of daily penalty should be caculated as per % of the amount of delay or failure in delivery or payment. or payment. But the total amount of penalty should not exceed % of the amount of nonperformance of the contract. If the party in breach has paid a margin in advance, the margin will be paid to the other party as a penalty at a certain rate or be deducted completely as stipulated.
12. Claim
In case the quality, specification, quantity, weight, package or sanitary condition are not in conformity with the contract, claim should be filed by the buyers within days after the arrival of the goods at destination. The buyers reserve the right to lodge a claim or ask for replacement on the strength of the inspection certificate issued by except when the insurance company or the carrier is liable.
13. Force Majeure
In case of force Mjeure ( war, civil war, earthquake, blockade, fire, flood etc. ) or fortuitous accident which interfers the excuting of this contract, the suffering party should furnish the other party with a certificate of force majeure accident issued by relative authority within days after the closure of the force majeure of fortuitous accident. In that case, the suffering may be immune from responsibility and both party should negotiate as to whether the contract must be cancelled or executed.
14. Arbitration
All disputes arising from the execution of contract or in connection with this contract shall be settled amicably through friendly negotiation between both parties or mediation by a third party ( including authority mediation and civil mediation). In the event that no settlement can be reached, the case in dispute
shall be submitted for arbitration to ( Foreign Trade Arbitration Commission of the China Council for the Promotion of International Trade, Kazakhzstan Industry and Commerce Commission or……) in accordance with the its provisional arbitration procedure and rules. The arbitral award is final and binding upon both parties. The arbitration expenses shall be borne by the losing party.
15. Executive Parties: upon contract, on behalf of the chinese party is (the conignor/ the consignee); on behalf the foreign party is (the conignor/ the consignee); the above parties should be liable all obligation of the contract.
16. Other Terms & Conditions
Other terms and conditions shall be subject to《The Common Delivery Terms》signed by PRC and the former USSR on May 13, 1990. An annex to the contract is an inseperable part of the contract. This contract is written in Chinese and English, both versions being authentic. This contract shall come into force after it is signed by the representatives of both parties. Each party holds a Chinese and an English copies.
The Buyers: The Sellers:
(Signature) (Signature)
Commodity List
Contract No:
Date: Annex No:
Name of commodity Specification Unit Quantity Unit Price(US$) Total Amount(US$) Time of Delivery
Total This commodity list in copies Total valus(capital) (US$) Port of Delivery Packing:
Consignee:
The sellers: The Buyers:
英文合同合同常用词 第一节合同常用词(Usual Wording)(1) 当大量接触英文合同，就会发现英文合同中有些词或短语出现的频率非常高，往往影响或决定了对 合同的准确理解，下面就分门别类从常见实词和常见虚词两个方面进行具体介绍： 一、英文合同常用虚词（Usual Function Words） 1．Here/there/where+介词构成的古体词 基本规则：Here 代表this，there 代表that，where 代表which 或what 即here/there/where+介词=介词 +this/that/which or what Hereby: by means of; by reason of this.特此，由此，兹等意。 例句：The Buyer hereby orders from the Seller the undermentioned goods
subject to the following conditions:买方向卖方订购下列商品，条件如下： Herein：in this。此中，于此。 例句：The minimum royalty herein specified shall be paid by Party B to Party A. 在此规定的最低特许权 使用费应由乙方付给甲方。 Hereinafter: later in the same Contract. 以下，在下文。通常与to be referred to as, referred as, called 连 用。 例句：This Agreement is made and concluded on ______, (date)____(year), by and between _____(hereinafter called Party A) on the one hand and _____(hereinafter called Party B) on the other hand. 本协议书于____年___月___日由_____（以下简称甲方）为一方，与_____(以下简称乙方)为另一方 签订。
编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载 英文合同格式 甲方：___________________ 乙方：___________________ 日期：___________________
NO.11 ZHONGSHAN STREET XIAMEN FUJIAN CHINA SALES CONFIRMATION ［打印预览］［保存］［诅出］ 销货合同（Sales Confirmation） 国际货物买卖合同一般金额大，内容繁杂，有效期长，因此许多国家的法律要求采用书面形式。书面合同主要有两种形 式，即正式合同（CONTRACT ）和合同确认书（CONFIRMATION ）,虽然其繁简不同，但具有同等法律效力，对买卖双方均有约束力。大宗商品或成交额较大的交易，多采用正式合同；而金额不大，批数较多的小土特产品或轻工产品，或者已订立代理、包销等长期协议的交易
多采用合同确认书（亦称简式合同）。 无论采哪种形式，合同抬头应醒目注明SALES CONTRACT 或SALES CONFIRMATION （对销售合同或确认书而言） 等字样。一般来说出口合同的格式都是由我方（出口公司）事先印制好的，因此有时在SALES CONFIRMATION 之前加上 出口公司名称或是公司的标志等（我外贸公司进口时也习惯由我方印制进口合同）。交易成立后，寄交买方签署 （countersign ）,作为交易成立的书面凭据。 在SimTrade 中，买卖双方都可以起草合同，填写时只需将名称、地址等内容作相应变化既可。如合同由买方起草时，上方空白栏则填入进口商公司名称及地址，以此类推。 报表上方两行空白栏 为出口商公司抬头，须分别填写出口商的英文名称及地址。 如:GRAND WESTERN FOODS CORP. Room2501, Jiafa Mansion, Beijing West road, Nanjing 210005, P. R. China Messrs 详细填列交易对象（即进口商）的名称及地址。 在SimTrade 中，进口商的详细资料请在淘金网”的公司库里查询。 如：Dynasty Furniture Manufacturing Ltd. 3344-54th Avenue S. E. Calgary, Alberta T2C OAS Canada No. 销货合同编号，由卖方自行编设，以便存储归档管理之用。 在SimTrade 中，该编号已由卖方在起草合同时填入，单据中不能再更改。 Date 填写销货合同制作日期。 如：2005年2月18日，可以有以下几种日期格式填法： 1.2005-02-18 或02-18-2005 2. 2005/02/18 或02/18/2005 3. 050218 （信用证电文上的日期格式） 4. February 18, 2005 或Feb 18, 2005 Product No. 填写货号，销货合同上应记明各种货物编号，以求联系沟通方便。 在SimTrade 中，货号必须选择淘金网”的产品展示”里已有的商品编号。 Description 品名条款。此栏应详细填明各项商品的英文名称及规格，这是买卖双方进行交易的物质基础和前提。对商品的具体描述说明是合同的主要条款之一，如果卖方交付的货物不符合合同规定的品名或说明，买方有权拒收货物、撤销合同并提出损害赔偿。 在SimTrade 中，商品的详细资料请在淘金网’产品展示”里查找，此栏目填写必须与淘金网的商品详细资料里商品英 文名称及英文描述完全一致。 例1 :产品01005 的商品描述: CANNED SWEET CORN 3060Gx6TINS/CTN 例2:产品04001 的商品描述：WOODEN TEA SERVICE
常见英文合同翻译与详解
引子:鉴于现在对外交流事例逐渐增多,英文合同特别是经济合同的翻译愈显重要,若译文不准确或不严谨,势必会引起不必要的经济纠纷.故今以一英文(经济)合同写作书籍为蓝本,录入一些有益文字,希望大家共同提高英文(经济)合同的翻译和写作。 合同文件是合同双方签订并必须遵守的法律文件,因此合同中的语言应体现其权威性.英文合同用语的特点之一就表现在用词上,即选择那些法律用词,以及正式用词,使合同表达的意思准确无误,达到双方对合同中使用的词无可争议的程度。 一.hereby 英文释义:by means of , by reason of this 中文译词:特此,因此,兹 用法:常用于法律文件、合同、协议书等正式文件的开头语；在条款中需要强调时也可用。 语法：一般置于主语后,紧邻主语. 例1： The Employer hereby covenants to pay the Contractor in consideration of the execution and co mpletion of the Works and the remedying of defects therein the Contract Price or such other s um as may become payable under the provisions of the Contract at the time and in the manne r prescribed by the Contract. 参考译文: 业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。 注释: (1)hereby: by reason of this 特此 (2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同 (3)completion of the Works: 工程的竣工 (4)therein: in the Works在本工程中 (5)the Contract Price: 合同总价,指工程的总造价 (6)such...as: 关系代词,相当于that, which (7)under: in accordance with 根据,按照 (8)the provisions of the Contract: terms and conditions of the Contract合同条款 例2： We hereby certify to the best of our knowledge that the foregoing statement is true and correc t and all available information and data have been supplied herein, and that we agree to provi de documentary proof upon your request. 注释： （1）hereby：特此 （2）to the best of our knowledge：as far as we know据我们所知 （3）foregoing statement：above-mentioned statement上述声明 （4）herein：in this, in the statement在声明中 （5）documentary proof：证明文件 参考译文： 特此证明，据我们所知，上述声明内容真实，正确无误，并提供了全部现有的资料和数据，我们同意，
合同 contract 合同编号(Contract No.) : 签订日期(Date) : 签订地点(Signed at) : 买方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Buyer:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 电话(Tel):___＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿ 电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 卖方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ The Seller:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ 地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿ Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿_＿ 电话(Tel):_＿＿＿＿＿＿＿＿传真(Fax):＿＿＿＿＿＿＿＿＿＿＿ 电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
买卖双方同意按照下列条款签订本合同： The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below: 1. 货物名称、规格和质量（Name, Specifications and Quality of Commodity）： 2. 保险（Insurance）：按协会货物条款A投保 To be effected by the seller. Covering all risks including war risk for 110% of the invoice value as per the clause of institute cargo clause (A) (January 1st , 1982). 3. 唛头（Shipping Marks）： 4. 装运口岸（Port of Loading）： 5. 目的口岸（Port of Destination）： 6. 装运期限（Time of Shipment）：收到全款55天内到货 WITHIN 55 DAYS AFTER RECEIVING THE PAYMENT. 7. 付款条件（Terms of Payment）： 信用证方式：买方应在装运期前/合同生效后＿＿日，开出以卖方为受益人的不可撤销的议付信用证，信用证在装船完毕后＿＿日内到期。 Letter of Credit: The Buyer shall, ______ days prior to the time of shipment /after this Contract comes into effect, open an irrevocable Letter of Credit in favor of the Seller. The Letter of Credit shall expire ____ days after the completion of loading of the shipment as stipulated. 8.单据（Documents Required）：
XIAOLING TRADE CO.,LTD NO.11 ZHONGSHAN STREET XIAMEN FUJIAN CHINA SALES CONFIRMATION Dear Sirs, [打印预览][保存][退出]
销货合同(Sales Confirmation) 国际货物买卖合同一般金额大，内容繁杂，有效期长，因此许多国家的法律要求采用书面形式。书面合同主要有两种形式，即正式合同（CONTRACT）和合同确认书（CONFIRMATION），虽然其繁简不同，但具有同等法律效力，对买卖双方均有约束力。大宗商品或成交额较大的交易，多采用正式合同；而金额不大，批数较多的小土特产品或轻工产品，或者已订立代理、包销等长期协议的交易多采用合同确认书（亦称简式合同）。 无论采哪种形式，合同抬头应醒目注明SALES CONTRACT或SALES CONFIRMATION（对销售合同或确认书而言）等字样。一般来说出口合同的格式都是由我方（出口公司）事先印制好的，因此有时在SALES CONFIRMATION之前加上出口公司名称或是公司的标志等（我外贸公司进口时也习惯由我方印制进口合同）。交易成立后，寄交买方签署（countersign），作为交易成立的书面凭据。 在SimTrade中，买卖双方都可以起草合同，填写时只需将名称、地址等内容作相应变化既可。如合同由买方起草时，上方空白栏则填入进口商公司名称及地址，以此类推。 报表上方两行空白栏 为出口商公司抬头，须分别填写出口商的英文名称及地址。 如：GRAND WESTERN FOODS CORP. Room2501, Jiafa Mansion, Beijing West road, Nanjing 210005, P. R. China Messrs 详细填列交易对象（即进口商）的名称及地址。 在SimTrade中，进口商的详细资料请在“淘金网”的公司库里查询。 如：Dynasty Furniture Manufacturing Ltd. 3344-54th Avenue S. E. Calgary, Alberta T2C OAS Canada No. 销货合同编号，由卖方自行编设，以便存储归档管理之用。 在SimTrade中，该编号已由卖方在起草合同时填入，单据中不能再更改。 Date 填写销货合同制作日期。 如：2005年2月18日，可以有以下几种日期格式填法： 1. 2005-02-18或02-18-2005 2. 2005/02/18或02/18/2005 3. 050218（信用证电文上的日期格式） 4. February 18, 2005或Feb 18, 2005 Product No. 填写货号，销货合同上应记明各种货物编号，以求联系沟通方便。 在SimTrade中，货号必须选择“淘金网”的“产品展示”里已有的商品编号。 Description
合同的英语单词 合同是当事人或当事双方之间设立、变更、终止民事关系的协议。依法成立的合同，受法律保护。那么你知道合同的英语单词是什么吗?下面来学习一下吧。 合同英语单词1： contract 合同英语单词2： agreement 合同英语单词3： paction 合同的英语例句： 他们有没有投标争取承包合同? Have they put in a bid for the contract? 根据你的合同，你每年有十五天的带薪假期。 According to your contract, you get 15 days paid holiday a year. 你的合同已经被终止。 Your contract has been terminated. 我们赢得了合同，但是却经过了多次不屈不挠的谈判才达到目的。 We won the contract but only through a lot of tough negotiating. 合同中有一条款禁止承租人转租房屋。
There is a clause in the contract forbidding tenants to sublet. 合同还可分为简单合同和正式合同。 Another way of classifying contracts is into simple and formal contracts. 在可撤销合同中，合同一方有权废止合同。 A voidable contract is one that a party will be entitled to rescind. 按照普通法，未成年人签订的合同除有效合同外就是可撤销合同或无效合同。 At common law contracts made with a minor that are not valid will be voidable or void. 我们对合同各项条款全无异议,下周签合同如何? We have agreed on all terms in the contract. 他们在合同上赔了钱。 They lost on the contract. 你要求在合同中订上什么条款? What clause do you require in the contract? 我想方设法从他嘴里套出他们另一些合同的细节。 I tried to pump him for details of their other contracts. 她三番五次地违反合同条款。 She violated the terms of the contract repeatedly. 你和你的配偶都需要签这份合同。 You and your spouse both have to sign this contract.
销售合同 SALES CONTRACT 买方：JOONAS&CO.,LTD, 10 LOUIS PASTEUR STEET POR T LOUIS MAURITIUS 合同号/Contract No: BF20100601 The Buyer : JOONAS&CO.,LTD, 10 LOUIS PASTEUR STEET PORT LOUIS MAURITIUS TEL：230-2400778 FAX: 230-2408285 卖方：唐山丰润百丰商贸 日期/Date: 2010-05-29 TEL: 0086 -315-5505831 FAX: 0086-315-5505833 The Seller: T angshan fengrun baifeng Trading Co.ltd 兹经买卖双方同意,由买方购进,卖方出售下列货物,并按下列条款签订本合同: This CONTRACT is made by and between the Buyers and Sellers; whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned goods on the terms and conditions stated below: Description of Goods: As follows. 1.原产地和制造厂家（Country of Origin and Manufacturer）： 中国China T angshan fengrun baifeng Trading Co.ltd 2.包装（Packing）：STANDARD EXPORT PACKAGING 3.Shipment（装运方式）：合同中货物全部用20’集装箱海运In Contract by 20’ Container. 4.装运期限（Time of Shipment）：WITHIN15-20 WORKING DAYS AFTER RECEIPT OF 30%T/T 5.装运口岸（Port of Loading）：上海中国SHANGHAI China 6.目的口岸（Port of Destination）：Port Louis, Mauritius 7.付款条款(T erms of Payment）：30%DOWN PA YMENT + 70% T/T AFTER RECEIVED THE COPY OF B/L 8.签约合同（Sign of Contract）：本合同传真有效This contract will valid for fax contract sign 9.人力不可抗议(Force Majeure)：由于水灾，火灾，地震，干旱，战争或协议一方无法预见，控制，避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责托。但是，受不可抗议力事件影响的一方必须尽快将发生的时间通知另一方，并在不可抗议力事件发生15（拾伍）天内将有关机构的不可抗议力事件的证明寄交对方。Either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood, fire, earthquake, draught, war or any other events which could not be predicted, controlled, avoided, or overcome by the relative party. However, the party affected by the event of Force Majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after it’s occurrence. 10. 货物要求（CRC requirements）: 10.1 每件货物重量大约5吨。Weight of Coils: About 5 tons
英文合同翻译汇总【是栓哥呕心沥血之作吗？】来源：卢瑞的日志 一.hereby 英文释义:by means of , by reason of this 中文译词:特此,因此,兹 用法:常用于法律文件、合同、协议书等正式文件的开头语；在条款中需要强调时也可用。 语法：一般置于主语后,紧邻主语. 例1： The Employ er hereby cov enants to pay the Contractor in conside ration of the execution and completio n of the Works and the remedy ing of defects therein the C ontract Price or such other sum as may become payable under the prov isions of the C ont ract at the time and in the manner prescribed by the C ontract. 参考译文: 业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。 注释: (1)he reby: by reason of this 特此 (2)cov enant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同 (3)completion of the Works: 工程的竣工 (4)therein: in the Wo rks在本工程中 (5)the C ontract Price: 合同总价,指工程的总造价 (6)such...as: 关系代词,相当于that, w hich (7)under: in accordance w ith 根据,按照 (8)the prov isions of the C ontract: terms and conditio ns of the C ontract合同条款 例2： We hereby certify to the best of our know ledge that the foregoing statement is true and correct and all av ailable information and data hav e been supplied herein, and that w e agree to prov ide documentary proof upon y our request. 注释： （1）hereby：特此 （2）to the best of our know ledge：as far as w e know据我们所知 （3）foregoing statement：abov e-mentioned statement上述声明 （4）herein：in this, in the statement在声明中 （5）documentary proof：证明文件 参考译文： 特此证明，据我们所知，上述声明内容真实，正确无误，并提供了全部现有的资料和数据，我们同意，应贵方要求出具证明文件。 例3： This C ontract is hereby made and concluded by and betw een C o. (hereinafter referred to as Party A) and C o. (hereinaft er referred to as Party B) on (Date), in (Place), C hina, on the principle of equality and mutual benefit and through amic able consultation. 注释： （1）hereby：特此 （2）hereinafter referred to as Party A：以下称甲方 （3）on the principle of equality and mutual benefit：在平等互利基础上 （4）through amicable consultation：通过友好协商 参考译文：
TABLE OF CONTENTS 1. Work to be Performed. 咨询事项 2. Compensation. 报酬 3. Independent Contractor Relationship. 对方各自独立的关系 4. Ownership of Work Product. 工作成果的所有权 5. Confidentiality. 保密 6. General Provisions. 一般性规定 This Consulting Contract is being entered into by X Company (“Client”) and Jane Doe (“Consultant”) this ____ day of . 1. Work to be Performed. 咨询事项 See attached project plan. 2. Compensation. 报酬 Client shall pay Consultant $ ___ per hour due on or before the first Friday following the end of any week in which Consultant performs services for Client. OR Client shall pay Consultant a flat fee of $___ as total compensation for the project described below. Payment shall be made as follows: a. $___ due before work will begin, and b. $___ due upon receipt of final deliverable. 3. Independent Contractor Relationship. 对方各自独立的关系 Consultant's relationship with Client will be that of an independent contractor, and nothing in this Agreement is intended to, or should be construed to, create a partnership, agency, joint venture, or employment relationship. No part of Consultant’s compensation will be subject to withholding by Client for the payment of any social security, federal, state ,or any other employee payroll taxes. 4. Ownership of Work Product. 工作成果的所有权 Consultant agrees that all work product developed by her alone or in conjunction with others in connection with the performance of services pursuant to this Agreement is and shall be the sole property of Client, and Consultant shall retain no ownership, interest, or rights therein. Work product includes but is not limited to reports, graphics, memoranda, slogans, and taglines. 5. Confidentiality. 保密 5.1 Definition of Confidential Information. "CONFIDENTIAL INFORMATION" as used in this Agreement shall mean any and all technical and non-technical information including patent, copyright, trade secret, proprietary information, computer files, and client information related to the past, current, future, and proposed services of Client and includes, without limitation, Client property, and Client's information concerning customers, research, financial information, purchasing, business forecasts, sales and merchandising, and marketing plans and information. 5.2 Nondisclosure and Nonuse Obligations. Consultant agrees to protect the confidentiality of all Confidential Information and, except as permitted in this section, Consultant shall neither use nor
英文合同样本 【各位读友，本文仅供参考，望各位读者知态，如若喜欢或者需要本文，可点击下载下载本文，谢谢！】祝大家工作顺利】 TIMBER SALE CONTRACT - SAMPLE The following document offers excellent guidelines when preparing a timber sale con tract.? Separate articles may be added to suit specific circumstances??lt is advised that the Seller and Purchaser employ legal coun sel to review the con tract prior to its
en dorseme nt. Con tract en tered into this ___ day of ,20 .,by and betwee n of Illi nois, here in after called the Seller, and ,of (city), (state ), Illi nois Timber Buyer Lice nse Number here in after called the Purchaser, WITNESSETH: 1. The Seller agrees to sell and the Purchaser agrees to buy for the total sum of dollars ($ __ ) under the conditions set forth in this
1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Tradi ng Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract This Contract is entered into this 5th day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿This Agreement was made on the＿day of＿19＿, BETWEEN ＿ (hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the Seller has agreed to sell and the buyer has agreed to buy ＿ (hereinafter referred to as the Goods ) the quantity, specification, and price of which are provided in Schedule A. IT IS HEREBY AGREED AS FOLLOWS: 5.Contract For Joint-Operation Enterprise ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party A”) AND ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party B”) Party A and Party B (hereinafter referred to as the “Parties”) agree to jointly form a Co-operation Venture Company (hereinafter referred to as the “CVC”) in accordance with “the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and the “Regulations for the Implementation of the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and other applicable laws and regulations. 6.MODEL CONTRACT Contract No. Date: Seller: Signed at: Address: Cable Address: Buyer: Address: Cable Address: The Seller and the Buyer have agreed to conclude the following transactions according to the terms and conditions stipulated below: of Commodity: 2.Specifications: 3.Quantity: 4.Unit Price: 5.Total Price: U.S.$: 6.Packing: 7.Time of Shipment: days after receipt of L/C. 8.Loading Port & Destination Port: From via to . 9.Insurance:
合同 CONTRACT 日期：合同号码： Date: Contract No.: 买方：(The Buyers) 卖方：(The Sellers) 兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品： This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter: (1) 商品名称: Name of Commodity： (2) 数量： Quantity: (3) 单价： Unit price: (4) 总值： Total Value: (5) 包装： Packing: (6) 生产国别： Country of Origin : (7) 支付条款： Terms of Payment: (8) 保险： Insurance: (9) 装运期限： Time of Shipment: (10) 起运港： Port of Lading:
(11) 目的港： Port of Destination: (12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不符，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。 Claims: Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable. The Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers. (13)不可抗力：由于人力不可抗力的原由，发生在制造、装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任。在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。 Force Majeure: The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after. The Sellers shall send by airmail to the Buyers for their acceptance certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods. (14）仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。 Arbitration: All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. In case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission. The Arbitration committee shall be final and binding upon both parties. And the Arbitration fee shall be borne by the losing parties.