Contract of Construction Project
合同编号：Contract Number:
工程名称：Project Name:
发包方（甲方）：工程设计顾问（北
京）
Employer (Party A): International Consulting Engineers ( Beijing) Limited
承包方（乙方）：中寰艺高建筑装饰工程有限公司
Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd
根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.
第一条工程项目Article 1, Project item
1．工程地点：Project site:
2. 工程范围：Scope of project
3. 工程造价：人民币元整(该造价为包工包料价)
Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)
第二条施工准备Article 2, Preparation for construction
1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。
Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles .
2．乙方：. Party B:
① 负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作；
Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area.
① 组织施工管理人员和材料、施工机械进场；
Organize construction management staff and construction materials, construction machinery enter the Site.
① 负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。
Be responsible for keeping public places clean during construction and packing construction material and leaving in the garbage collection place designated by management office each day.
第三条工程期限Article 3Period of Construction
1. 根据工期和使用需要，商定工程总施工期为天（日历天），自年月日开工
至年月日完工
According to the period of construction and the use need, the total construction period agreed shall be days (Calendar days), start from the date of and complete on the date of.
2．如遇下列情况，经甲方现场代表签证后，工期相应顺延：
Construction period shall be prolonged upon Party A site representative's confirmation when the matters occur as follows.
① 按施工准备规定，甲方未协助乙方办理临时水电及垂直运输,影响进场施工；According to the requirements of construction preparation, Party A fail tot assist Party B to apply for temporary water and electricity and vertical transportation and have an impact on Party B construction;
① 因甲方提出增减项目而造成重大设计变更，因而影响进度；
The material modification or change of design due to the party A’ s requirement of addition or deletion of project have the effect of hindrance on the progress of works.
① 未按合同规定拨付预付款、工程款而影响施工；
Party A fail to pay the advance payment and construction cost to party B and impact the construction progress;
①人力不可抗拒的因素而延误工期。
The delay of schedule of construction due to Force Majeure.
第四条工程质量Article 4The quality of project
一．本工程质量经双方研究要求达到双方约定之验收标准。
The quality of project should achieve the requirements of acceptance agreed by both parties.
二．乙方必须严格按照施工图纸、说明文件和国家颁发的建筑工程规范、规程和标准进行施工，并接受甲方的监督。
Party B should carry on the construction in strict accordance with drawing, specification file and regulations and specifications authorized by the competent authorities and be under the supervision of Party A.
三．乙方在施工过程中必须遵守下列规定：Party B should, during the construction, comply with the provisions as follows:
1．由乙方提供给甲方的所有材料必须经甲方同意方可使用，未按要求购买严禁使用；
All materials provided by Party B should be subject to the approval of Party A prior to use, And none of the same being bought without conformity with Party A requirements can be used.
2．隐蔽工程必须经甲乙双方检查，方可进行下一道工序；
The concealed works should be checked by both parties before the next progress;
3．工程竣工后，乙方按规定对工程实行保修，保修时间自通过竣工验收之日算起，保修
期一年。
Party B shall take the liability of maintenance following the complete of works. The period of maintenance shall be one year from the day of acceptance of complete.
第五条工程价款的支付与结算Article 5Payment and settlement of the contract price
合同总价× 50%, 即元The total contract price × 50%, which is Yuan.
中期款The payment of medium-term
工程进度过半三日内Within 3 (three) days after the progress more than half.
合同总价× 40%, 即元The total contract price × 40%, which is Yuan.
尾款Final Payment
竣工验收结算后七日内Within 7 (seven) days after the completion acceptance and settlement.
合同总价× 10 %, 即元The total contract price × 10%, which is Yuan.
第六条施工与设计变更Article6 The Modification of Construction and Design
一．乙方交付的设计图纸、说明和有关技术资料，作为施工的有效依据，开工前由甲方组织签字认同，作为施工的补充依据，甲、乙双方均不得擅自修改。
Design drawing, illustration and relevant technical data consigned by party B are the basis for construction and shall be confirmed by party A’s signature, which is deemed as the supplementary basis and shall be modified by any party without authorization.
二．施工中如发现因甲方要求而发生的设计错误或严重不合理的地方，乙方应及时以书面形式通知甲方，由甲方及时会同乙方等有关单位研究确定修改意见或变更设计文件，乙方按修改或变更的设计文件进行施工。若发生增加费用（包括返工损失、停工、窝工、人员和机构设备调迁、材料构配件积压的实际损失）由甲方负责，并调整合同造价。
If and when any error or material unreasonable problem of design due to party A’s requirement, Party B shall notify Party A promptly in writing and decide the amendment or modification of the design documentation by the consultation and negotiation between parties and units concerned. Party B shall carry out construction according to the design documents modified or changed. If project cost increase (including the actual loss of rework loss, stoppage or slowdown, personnel and machine equipment relocated, material structures, fixtures backlog), shall be responsibility by Party A, and be adjusted the contract price together with Party B.
三．乙方在保证工程质量和不降低设计标准的前提下，提出修改设计、修改工艺的合理化建议，经甲方、设计单位或有关技术部门同意后采取实施。
Any reasonable suggestion on the modifications of design and craft proposed by Party B, subject to the quality and without reducing standards of design, could be carried out upon the approval of Party A, design unit or concerned technical department.
四．甲方如需设计变更，必须作出正式修改通知书和修改图纸，乙方才予实施。重大修改和增加造价时，必须另行协商，乙方才予实施。
Party A should, if any necessary design change, make the formal amendment and modify drawings for Party B’s implementation.. Material changes and cost increased must be negotiated by both parties before Party B implement the same.
第七条工程验收Article 7Acceptance of project
一．工程施工中地下工程、结构工程必须具有隐蔽验收签证、试水、抗渗等验收合格记录。甲方须及时办理验收签订手续。
The underground engineering, structural engineering in the construction of project should be checked and with issue of certificate and the record of acceptance of water test, anti-permeability and so on. Party A should deal with the acceptance signed formalities timely.
二．工程竣工验收后，甲方才可使用Party A can use the project after completion acceptance
在规定的保修期内，凡因施工造成的质量缺陷应由乙方无偿保修。其保修条件、范围和期限按城乡建设环境保护部（84）城建字第79号通知印发的《建筑工程保修办法（试行）》执行。
In the provision warranty period, any construction quality defects, Party B should make maintenance free of the quality defect due to construction, the scope and duration carry out according to the issuance of Cheng Jian No. 79 notification " Construction engineering guarantee measures (Trial) "by Urban and Rural Construction and Environmental Protection Department (84).
第八条违约责任Article 8Liability for breach of contract
乙方的责任：Responsibility of Party B:
一．工程质量不符合合同规定的，负责无偿修理和返工。
Take charge of gratis repair and rework if project quality doesn't meet contact's stipulation
二．工程不能按合同规定的工期交付使用的，按合同中关于建设工期提交或拖后的奖罚规定偿付逾期罚款。
If fail to deliver the construction according to the contract on time, The overdue fines according to punishment or award of the provision concerning the delivery or delay.
甲方的责任：The responsibility of Party A:
一．未能按照合同的规定履行自己应负的责任，除竣工日期得以顺延外，还应赔偿乙方由此造成的实际损失。
Failed to fulfill their responsibilities in accordance with the provisions of the contract, in addition to the completion date to be postponed should be compensation for the actual loss of Party B .
二．工程中途停建、缓建或由于设计变更以及设计错误造成的返工，应采取措施弥补或减少损失。同时，赔偿乙方由此造成的停工、窝工、返工、倒运、人员和机械设备调迁、材料和构件积压的实际损失。
The ongoing project is stopped, postponed or due to design changes and rework caused by design errors, should take measures to remedy or reduce losses. At the same time, compensate Party B the actual loss of work stoppage, slowdown, re-dispatch rework, reshipment, staff and mechanical equipment relocating, the backlog of materials and components.
第九条纠纷解决办法Article 9 Dispute settlement
任何一方违反合同规定，双方协商不成，均可向北京仲裁委员会申请仲裁。
Either party could, if any party’s breach and fail to negotiation, submit the application of arbitration to the Beijing Arbitration Committee
第十条附则Article 10 Supplementary
一．本合同一式贰份，甲乙双方各执正本一份。
This contract is execute in two counterparts, each party holds a single original.
二．本合同自双方代表签字，加盖双方公章或合同专用章即生效。工程竣工验收符合要求，待保修期满后合同终止。
The contract becomes effective after signing and sealing by both parties on this foregoing date. The project final acceptance meet the requirements, after the expiry of warranty,
ends the contract.
甲方（盖章）：Party A (seal): 乙方（盖章）：Party B (seal): 委托代理人（签章）：Agent委托代理人（签章）：
Agent
电话：Tel: 电话：Tel:
日期：Date:日期：Date:
1.Sales Agreement The agreement, (is) made in Beijing this eighth day of August 1993 by ABC Trading Co., Ltd., a Chinese Corporation having its registered office at Beijing, the People’ Repubic of China (hereinafter called “Seller”) and International Tradi ng Co., Ltd., a New York Corporation having its registered office at New York, N.Y., U.S.A. (hereinafter called “Buyer”). 2.WITNESSETH WHEREAS, Seller is engaged in dealing of (product) and desires to sell (product)to Buyer, and WHEREAS, Buyer desires to purchase(product) from Sellers, Now, THEREFORE, it is agreed as follows: 3.Export Contract This Contract is entered into this 5th day of August 1993 between ABC and Trading Co., Ltd. (hereinafter called “Seller”) who agrees to sell, and XYZ Trading Co., Ltd. (hereinafter called “Buyer”) who agrees to buy the following goods on the following terms and condition. 4.Non-Governmental Trading Agreement No. ＿＿This Agreement was made on the＿day of＿19＿, BETWEEN ＿ (hereinafter referred to as the Seller) as the one Side and ＿ (hereinafter referred to as the Buyer) as the one other Side. WHEREAS, the Seller has agreed to sell and the buyer has agreed to buy ＿ (hereinafter referred to as the Goods ) the quantity, specification, and price of which are provided in Schedule A. IT IS HEREBY AGREED AS FOLLOWS: 5.Contract For Joint-Operation Enterprise ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registered office at (hereinafter called “Party A”) AND ＿＿ COMPANY LTD., a company duly organized under the Law of ＿＿ and having its registere d office at (hereinafter called “Party B”) Party A and Party B (hereinafter referred to as the “Parties”) agree to jointly form a Co-operation Venture Company (hereinafter referred to as the “CVC”) in accordance with “the Laws of the People’s Republic of C hina on Joint Ventures Using Chinese and Foreign Investment” and the “Regulations for the Implementation of the Laws of the People’s Republic of China on Joint Ventures Using Chinese and Foreign Investment” and other applicable laws and regulations. 6.MODEL CONTRACT Contract No. Date: Seller: Signed at: Address: Cable Address: Buyer: Address: Cable Address: The Seller and the Buyer have agreed to conclude the following transactions according to the terms and conditions stipulated below: http://biz.doczj.com/doc/bb15926675.html, of Commodity: 2.Specifications: 3.Quantity: 4.Unit Price: 5.Total Price: U.S.$: 6.Packing: 7.Time of Shipment: days after receipt of L/C. 8.Loading Port & Destination Port: From via to . 9.Insurance:
销售合同 SALES CONTRACT 编号：Contract No: 日期: Date: 签约地点：Signed at: 卖方：Sellers: 地址：Address: 邮政编码：Postal Code: 电话：Tel:传真：Fax: 买方：Buyers: 地址：Address: 邮政编码：Postal Code: 电话：Tel:传真：Fax: 兹确认售予买方下列货品，其成交条款如下： The Seller hereby confirms selling the following goods on terms and conditions specified as (3)公差：数量及总值均有_____%的增减,由卖方决定 Tolerance: With _____% more or less both in amount and quantity allowed at the sellers option. (4) 原产地
Country of Origin: (5) 付款方式：30%预付，70%发货前一周付清 Payment terms: 30% deposit, 70% payment within one week before delivery. (6) 交货时间：收到预付款后15天内完成装运。 Time of shipment: Within15 days after deposit received. (7) 贸易方式：FOB Shanghai Terms of Shipment: FOB Shanghai (8) 包装：胶合板木盘外封铁皮 Packing：Plywood drum with steel sheet cover. (9) 保险：由卖方按发票全额110%投保至_____为止的_____险。 Insurance：To be effected by seller for 110% of full invoice value covering _____ up to _____ only. (10) 装运口岸：中国上海港 Port of Loading: Shanghai Port, China (11) 转运：允许 Transshipment: Allowed (12) 分批装运：允许分批装运 Partial Shipment: Allowed (13) 目的口岸： Port of Destination: (14) 唛头：Shipping Marks： (15) 单据：Documents： (16) 品质与数量、重量的异义与索赔：Quality/Quantity Discrepancy and Claim： (17) 逾期发运：如果由于买方原因造成逾期发运，买方承担责任。造成自签订合同之日起超过45天不能发运的，卖方将每日按货物金额的3%收取保管费；如果由于买方原因造成逾期发运超过6个月，卖方有权自行处置定金和货物。如果是卖方原因造成的逾期
Memorandum of Understanding This Memorandum of Understanding(MOU)is made and entered into this 8th day of sep,2012 between: The Consortium whose principal place of business is in PRC and consisting,inter alia of i)China International Fund Limited; ii)China Railway Construction Corporation; (the Consortium)of the one part, and the Government of the Republic of Sierra Leone(GOSL) The Consortium and GOSL are sometimes referred to in this MOU individually as a “Party”and,collectively, as the “Parties” WHEREAS A. In furtherance of the mutual desires of the Parties to develop a strategic partnership and cooperation to ensure that the rich potential resources of Sierra Leone benefit the people of Sierra Leone through improved welfare of the People of Sierra Leone through the provision of services and infrastructure and the strengthening of Sierra Leone’s national development through experience sharing(South-South Cooperation) particularly in the sphere of construction of core infrastructure assets; B.To bring to the People of Sierra Leone, in the spirit of mutual respect and with a view of transferring relevant technical, organizational and management skills necessary to bring to the C.Republic of Sierra Leone to a higher level of development and prosperity; D.GOSL desires assistance in sourcing,implementing or prequalifying skilled and competent contractors and financiers for the purpose of its national development priorities award of contracts for projects specifically in the following priority areas; 1.MINISTRY OF WORKS,HOUSING AND INFRASTRUCTURE - Remedial Roads Rehabilitation - Development of new city - Construction and Operation of Ⅰ) Affordable Social Housing Infrastructure Ⅱ) National trunk and feeder roads Ⅲ) National railways Ⅳ) Bridges and drainage systems at national ,regional and local levels Ⅴ) Airports 2.MINISTRY OF ENERGY AND WATER RESOURCES: - Construction and operation of: Ⅰ) Thermal electric generation systems Ⅱ) Hydro power systems & infrastructure Ⅲ) Water supply systems & infrastructure Ⅳ) Other renewable power generation systems 3.PETROLEUM DIRECTORATE
合同意向书范本 潜在资产出让合同意向书 潜在卖方：_____________________________ 潜在买方：_____________________________ 交易事项：_____________________________ 日期：______________, 20_____ 本意向书不具有约束力，所包含之条款有待上述潜在卖方与买方就可能发生之交易（本处应指“资产出让”）进行磋商。本意向书不应被视为任何合同、或具有法律约束力的协议，而应视作仅为磋商之目的而订立的有关本意向书项下可能达成之合同的条款概述。签署本意向书之目的是为了能够便于潜在买方就购买价格筹措资金。双方应对本意向书之内容保密，且除了本意向书项下双方及其雇员、律师、会计师和潜在买方之潜在贷款方之外，不得向任何其他第三方透露。本次磋商之交易条款随附其后，但是除非潜在的买卖双方签署书面协议，这些条款（及潜在出让本身）将不具有约束力。随附条款中“应该”一词仅为合同阅读之惯例，并不意味随附之条款具有或将要具有法律约束力。 ____________________________ 签字 ____________________________ 签字 LETTER OF INTENT FOR POSSIBLE CONTRACT FOR SALE OF ASSETS Possible Seller: _____________________________ Possible Buyer: _____________________________ Business: _____________________________ Date: ______________, 20_____ This is a non-binding letter of intent that contains provisions that are being discussed for a possible sale of the Business named above from the possible Seller named above to the possible Buyer named above. This is not a contract. This is not a legally binding agreement. This is merely an outline of possible contract terms for discussion purposes only. This is being signed in order to enable the Possible Buyer to apply for financing of the purchase price. This letter of intent is confidential and shall not be disclosed to anyone other than the parties and their employees, attorneys and
Both parties jointly acknowledge and abide by their responsibilities and obligations and reach an agreed result. 甲方：___________________ 乙方：___________________ 时间：___________________ 中英文合同
编号：FS-DY-20628 中英文合同 建筑合同architecture confirmation 甲方：party a：乙方：party b： 合同编号：contract no 日期：date： 签约地点：signed at： 特约定： 甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____（涉约建筑）。涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为合同附件的设计图和施工细则中予以说明。 witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and
finish a libarary building for party b. （the building hereinafter is referred to as the said building.）the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed. 基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。支付方法商定如下： in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit： 在上述工程开工之日，支付人民币_____元整 在_____年_____月_____日，支付人民币_____元整 在_____年_____月_____日，支付人民币_____元整 在_____年_____月_____日，支付人民币_____元整 在_____年_____月_____日，支付人民币_____元整 余额人民币_____元整于工程完成之日付清。 rmb_____at the beginning of the said work. rmb_____on _____/ _____/_____（for example：3/21/XX）
英文销售合同_中英文对照销售合同范本英文销售合同_中英文对照销售合同范本(一) SALES CONTRACT 合同编号： Contract NO: 签订地点： Signed at: 签订日期： Date: 买方： The Buyers： 卖方： The Sellers： 双方同意按下列条款由买方售出下列商品：
The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below： (1)商品名称、规格及包装 (1)Name of Commodity ,Specifications and Packing (2)数量 (2)Quantity (3)单价 (3)Unit Price (4)总值 (4)Total Value (装运数量允许有 %的增减) (Shipment Quantity %more or less allowed) (5)装运期限：
(5)Time of Shipment： (6)装运口岸： (6)Port of loading： (7)目的口岸： (7)Port of Destination： (8)保险;由方负责，按本合同总值110%投保_____险。 (8)Insurance：To be covered by the___for 110% of the invoice value against_______. (9)付款：凭保兑的、不可撤销的、可转让的、可分割的即期有电报套汇条款/见票/出票____天期付款信用证，信用证以_____为受益人并允许分批装运和转船。该信用证必须在______前开到卖方，信用证的有效期应为上述装船期后第15天，在中国______到期，否则卖方有权取消本售货合约，不另行通知，并保留因此而发生的一切损失的索赔权。
Contract of Construction Project 合同编号：Contract Number: 工程名称：Project Name: 发包方（甲方）： Employer (Party A): 承包方（乙方）： Contractor (Party B): 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract. 第一条工程项目Article 1, Project item 1．工程地点：Project site: 2. 工程范围：Scope of project 3. 工程造价：人民币元整(该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备Article 2, Preparation for construction 1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2．乙方：. Party B: ①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. ②组织施工管理人员和材料、施工机械进场； Organize construction management staff and construction materials, construction machinery enter the Site. ③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。 Be responsible for keeping public places clean during construction and packing
YOUR LOGO 中英文合同意向书范本正式版 After The Contract Is Signed, There Will Be Legal Reliance And Binding On All Parties. And During The Period Of Cooperation, There Are Laws To Follow And Evidence To Find 专业合同范本系列，下载即可用
中英文合同意向书范本正式版 使用说明：当事人在信任或者不信任的状态下,使用合同文本签订完毕，就有了法律依靠,对当事人多方皆有约束力。且在履行合作期间,有法可依,有据可寻，材料内容可根据实际情况作相应修改，请在使用时认真阅读。 (sample letter of intent form) letter of intent for possiblecontract for sale o f assetspossible seller: _______________possible bu yer: _______________business: _______________date: _ _____________, 20_____ this is a non- binding letter of intent that contains provisions that are being discussed for a possible sale of the business named above from the possible s eller named above to the possible buyer named a bove. this is not a contract. this is not a l egally binding agreement. this is merely an outl ine of possible contract terms for discussion pu rposes only. this is being signed in order to enable the possible buyer to apply for financing of the purchase price. this letter of intent is confidential and shall not be disclosed to a nyone other than the parties and their employees
中英文合同范本 建筑合同architecture confirmation 甲方：party a：乙方：party b： 合同编号： contract no 日期：date： 签约地点：signed at： 特约定： 甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在 订约日期之翌日起_____天之内为乙方建造并完成_____（涉约建筑）。涉约建 筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为 合同附件的设计图和施工细则中予以说明。 witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. （ the building hereinafter is referred to as the said building.） the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed. 基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。支付方法商定如下： in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one
工程施工合同 Contract 合同编号( Contract NO. )： 签订日期( Date )： 发包方（简称甲方） Party A: 承包方（简称乙方）： Party B: 根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。 According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect. 1.工程概况 Project overview 1.1工程名称： Project name: 1.2工程地点： Project location: 1.3工程范围： A. 新研发中心和新厂房的网络综合布线系统的施工； B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。 Project contents: A. The new R & D and new plant construction of network cabling systems; B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems. 1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。 Start conditions: After the commencement of the contract, Party A has started advance and on-site conditions in place.
房屋租赁合同中英文合同范本 lease contract 出租方(甲方)lessor (hereinafter referred to as party a) ： 承租方(乙方)lessee (hereinafter referred to as party b) ： 根据国家有关法律、法规和有关规定，甲、乙双方在平等自愿的基础上，经友好协商一致，就甲方将其合法拥有的房屋出租给乙方使用，乙方承租使用甲方房屋事宜，订立本合同。 in accordance with relevant chinese laws 、 decrees and pertinent rules and regulations ,party a and party b have reached an agreement through friendly consultation to conclude the following contract. 一、物业地址 location of the premises 甲方将其所有的位于上海市_________区____________________________________的房屋及其附属设施在良好状态下出租给乙方___________使用。 party a will lease to party b the premises and attached facilities all owned by party a itself, which is located at _______________________________________ __________________________ and in good condition for_____________ . 甲方如未按本合同规定的时间向乙方提供租赁房屋，应按延迟期间内乙方应交租金的_____%计算，向乙方偿付违约金。 1-该房屋的现有装修及设施状况，由双方在合同附件( )中加以列明。除双方另有约定外，该附件作为甲方按本合同约定交付乙方使用和乙方在本合同租赁期满交还该房屋时的验收依据。 二、房屋面积 size of the premises 出租房屋的登记面积为_________平方米(建筑面积)。 the registered size of the leased premises is_________square meters (gross size). 三、租赁期限 lease term
xxx engineering contract xxx工程合同 Contract No.: 合同编号： Party A: xxxCompany Limited 甲方：xxx有限公司 Party B:xxx Company Limited 乙方：xxx有限公司
This contract is made and entered into on the day of , 2014 by the following Parties in . 本合同于2014年月日由以下当事方在签署。 Party A: xxx Company Limited, 甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxx Party B:xxx Company Limited, 乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party. 甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。 1. Work Content and Requirements 1. 工作内容、要求 1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Project standard and quality standard stipulated by Ministry of Engineering of the Union of xx. 1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。 2. Contract Period 2. 合同期限 2.1 Work period for the Road Construction Project: the work shall be completed within 2 month upon signing the Contract. The condition of handover is that the Project Inspection & Acceptance Team constituted by Party A, shall issue the Inspection & Acceptance Sheet after onsite inspection. 2.1 本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具 验收单为竣工交接条件。 2.2 This contract shall be implementedafter this is duly signed by the legal representatives or authorized representatives of the Parties and stamped with the seals of the Parties, and closed after the onsite acceptance of the Project and Contract payment. 2.2 本合同自双方法定代表人或授权代表人签字盖章后生效，现场验收合格、款项支付完毕后关闭。 3. Health, Safety and Environment Principles (HSE) 3. 健康、安全和环境原则(HSE) 3.1 The staff from Party B shall follow the arrangement of Local government and Party A (or its representatives), and comply with the laws and regulations of Myanmar as well as rules and regulations on Health, Safety and Environment (HSE) of Party A. 3.1 乙方工作人员必须听从地方政府、甲方人员（或代表）的安排，遵守缅甸法律、法规和甲方的安全 环境健康规章制度等。 3.2 Before or during the implementation of this Project, Party B shall acknowledge, avoid and prevent the possible damage of the Project to the surrounding environment and other affiliatedfacilities, and the resulting losses shall be borne by Party B.
(sample letter of intent form) letter of intent for possible contract for sale of assets possible seller: _____________________________ possible buyer: _____________________________ business: _____________________________ date: ______________, 20_____ this is a non-binding letter of intent that contains provisions that are being discussed for a possible sale of the business named above from the possible seller named above to the possible buyer named above. this is not a contract. this is not a legally binding agreement. this is merely an outline of possible contract terms for discussion purposes only. this is being signed in order to enable the possible buyer to apply for financing of the purchase price. this letter of intent is confidential and shall not be disclosed to anyone other than the parties and their employees, attorneys and accountants and the possible lenders of the possible buyer. the terms of the transaction being discussed are attached hereto, but the terms (and the possible sale itself) are not binding unless and until they are set forth in a written contract signed by possible seller and possible buyer. the word "shall" is used in the attached terms only as an example of how a contract might read, and it does not mean that the attached terms are or ever will be legally binding. ____________________________ ________________________ ____________________________